Are You Sure?

PUBLIC NOTICE Notice is hereby given that bid proposals will be received from Bidders classified under N.J.S.A. 27:7-35.2 via the Internet until 10:00:59 A.M. on 1/16/25 downloaded, and publicly opened and read, in the CONFERENCE ROOM-A, 1st Floor F & A Building, New Jersey Department of Transportation, 1035 Parkway Avenue, Trenton, NJ 08625; for: Long-Life Pavement Marking Contract Central, Cycle 3 (2025), Hunterdon, Mercer, Middlesex, Monmouth, Ocean, Somerset and Warren (South of Route 57) Counties Federal Project No: STBGP-FLEX-D00S(929) DP No: 25461 Bidders are required to comply with the requirements of Title VI of the Civil Rights Act of 1964. Specifically, the contractor, sub recipient or subcontractor shall not discriminate on the basis of race, color, national origin, or sex in the performance of this contract. The contractor shall carry out applicable requirements of 49 C.F.R. Part 26 in the award and administration of DOT-assisted contracts. Failure by the contractor to carry out these requirements is a material breach of this contract, which may result in the termination of this contract or such other remedy as the recipient deems appropriate. Pursuant to N.J.S.A. 52:32-44, contractor must submit the Department of Treasury, Division of Revenue Business Registration of the contractor and any named subcontractors prior to contract award or authorization. Pursuant to N.J.S.A. 34:11-56.51, contractors must be registered with the New Jersey Department of Labor, Division of Wage and hour Compliance at the time of bid. The Department, in accordance with Title VI Civil Rights Act of 1964, 78 Stat. 252 U.S.C., 49 C.F.R., Parts 21 and 23 issued pursuant to such Act, and Section 504 of the Rehabilitation Act of 1973 will afford minority business enterprises full opportunity to submit bids in response to this invitation and will not discriminate against any bidder on the grounds of race, color, sex, national origin, or handicap in the project award. Plans, specifications, any addenda to the specifications, and bidding information for the proposed work are available at Bid Express website www.bidx.com. You must subscribe to use this service. To subscribe, follow the instructions on the web site. Fees apply to downloading documents and plans and bidding access. The fee schedule is available on the web site. All fees are directly payable to Bid Express. Plans, specifications, any addenda to the specifications, and bidding information may be inspected ( BUT NOT OBTAINED ) by contracting organizations at our various Design Field Offices at the following locations: 200 Stierli Court One Executive Campus Rt. 70 West Mt. Arlington, NJ 07856 Cherry Hill, NJ 08002 Phone: 973-601-6690 Phone: 856-486-6623 New Jersey Department of Transportation Division of Procurement Bureau of Construction Services 1035 Parkway Avenue PO Box 600 Trenton, NJ 08625 3x, CP, PP, 12/20, 12/27/24, 1/3/25, Fee:$322.44

L E G A L N O T I C E Notice is hereby given that the PLANNING BOARD OF PRINCETON at a regular meeting on DECEMBER 19, 2024 adopted the Findings of Fact for the following application: APPLICANT: STEVEN WASKOW Minor Subdivision for Lot Line Adjustment File #P2323-368MS LOCATION: 537 and 561 Stockton Street; Block 9301, Lots 11 and 12 NATURE OF APPLICATION: Lot line adjustment to accommodate the future relocation of a historic structure out of the flood hazard area. A copy of all documents are on file in the office of the Planning Board of Princeton, 400 Witherspoon Street; Princeton, NJ and may be viewed during normal business hours. Kerry A. Philip, Board Secretary PRINCETON PLANNING BOARD 1x, PP, 12/27/24, Fee:$20.01 Affidavit Fee:$15.00

BOROUGH OF JAMESBURG LEGAL NOTICE NOTICE IS HEREBY GIVEN TO ALL PROPERTY OWNERS IN THE BOROUGH OF JAMESBURG THAT THE ASSESSMENT BOOK FOR THE YEAR 2025 WILL BE OPEN FOR PUBLIC INSPECTION AT BOROUGH HALL, 131 PERRINEVILLE ROAD, JAMESBURG, NJ ON FRIDAY, JANUARY 3, 2025 BETWEEN THE HOURS OF 10:00 AM AND 3:00 PM Ken Pacera Tax Assessor 1x. CP, 12/27/24, Fee:$7.78

HUNTERDON COUNTY SHERIFF'S SALE # 4065 SUPERIOR COURT OF NEW JERSEY CHANCERY DIVISION, HUNTERDON COUNTY DOCKET F-003493-23 J.P. MORGAN MORTGAGE ACQUISITION CORP VS NICHOLAS GATELY; ET AL. Execution for sale of mortgaged premises. By virtue of a Writ of Execution in the above stated action to me directed and delivered, I shall expose for sale at public venue and sell to the highest bidder on: Wednesday, January 8, 2025 at 2:00 p.m. in the afternoon prevailing time, at the Sheriff's Office, 71 Main Street, Commissioners Meeting Room 2nd Floor, Borough of Flemington, that is to say: Property to be sold is located in the TOWNSHIP OF WEST AMWELL County of Hunterdon, State of New Jersey Premises commonly known as: 713 BRUNSWICK PIKE LAMBERTVILLE, NJ 08530 Tax LOT 22 BLOCK 30 Dimensions: (approx.): 2.06 AC Nearest Cross Street: HEWITT ROAD The foregoing concise description does not constitute a full legal description of the property of which a full legal description may be found in the Office of the Hunterdon County Sheriff. The Sheriff hereby reserves the right to adjourn this sale without further publication. The approximate amount due on the above execution is the sum of $226,284.06 together with lawful interest and costs of this sale. A deposit of 20% of the purchase price in cash or certified funds is required at the Close of the sale. *Taxes- at time of inquiry- taxes paid through 3rd quarter 2024; 4th quarter 2024 taxes open in the base amount of $2,103.76 and due 11/1/2024; *Water - at the time of inquiry - Private account, verification of same prohibited without authorization of record property owner; *Sewer - Private account, verification of same prohibited without authorization of record property owner; (XX) Subject to: If property is located in a Homeowner's Association, then it is sold subject to any assessments and other fees which may be responsibility of new owner under NJ Supreme Court case of Highland Lakes Country Club & Community association v. Franzino, 186 N.J. 99 (2006); (XX) Subject to: If property is located in a condominium or Homeowner's Association, then it may be sold subject to a rolling 6-month limited priority lien of the condo association; (XX)Subject to: *If the subject property is a part of an age restricted community, you must be 55 and older and intend to reside in the property or you may be precluded membership in the community. *Also subject to subsequent taxes, water and sewer plus interest through date of payoff. SURPLUS MONEY: If after the sale and satisfaction of the mortgage debt including costs and expenses, there remains any surplus money, the money will be deposited into the Superior Court Trust Fund and any person claiming the surplus, or any part thereof, may file a motion pursuant to Court Rules 4:64-3 and 4:57-2 stating the nature and extent of that person’s claim and asking for an order directing payment of the surplus money. The Sheriff or other person conducting the sale will have information regarding the surplus, if any. ATTORNEY FOR THE PLAINTIFF Frederick W. Brown, SHERIFF ROMANO GARUBO & ARGENTIERI HUNTERDON COUNTY (856)384-1515 DATED: 9/26/2024 4x, HV, 12/13, 12/20, 12/27/24, 1/3/25, Fee:$186.08 Affidavit Fee:$15.00

NOTICE OF DECISION HILLSBOROUGH TOWNSHIP HISTORIC PRESERVATION COMMISSION The Hillsborough Township Historic Preservation Commission held a public meeting on Thursday, December 19, 2024, at 7:30 p.m. in the Municipal Courtroom at The Peter J. Biondi Building, at which time the following Resolution was memorialized: Phoenix Carriage Farm, LLC- File #HHPC-24-01 (BA-24-07) – Applicant GRANTED favorable recommendation for construction of four two-story townhouse buildings with 46 residential units, four walkup storage container restaurants, an amphitheater/stage, bathroom facility and other various site improvements on the Property known as Block 200.10, Lot 4 on the Hillsborough Townshp Tax Maps, located at 2 Clerico Lane, in the GC, Gateway ‘C’ Zone. The Subject Property is identified in the Historic Preservation Plan Element, Hillsborough Township Master Plan, Township of Hillsborough Somerset County, Adopted April 5, 2001, as located within the Proposed Clerico Lane Historic District, and listed as Hillsborough Historic Site #36 (“Van Nuys House”). The above-referenced Resolution has been filed in the Planning & Zoning Department and is available for public inspection at The Peter J. Biondi Building, 379 South Branch Road, Hillsborough, NJ 08844 during the business hours of 8:30 a.m. to 4:00 p.m. Debora Padgett Administrative Assistant / Planning Board Clerk 1x, HB, 12/27/24, Fee:$24.17

THE TOWNSHIP OF HILLSBOROUGH MUNICIPAL UTILITIES AUTHORITY REQUEST FOR QUALIFICATIONS & PROPOSAL BOND COUNSEL The Township of Hillsborough Municipal Utilities Authority (TTHMUA) is issuing a Request for Qualifications & Proposal (RFQ/RFP) from Bond Counsels licensed to practice in the State of New Jersey who specialize in Authorities to provide professional legal services, to give legal advice and opinions, to be available as needed for consultation with the TTHMUA and staff and, in general, to handle special legal work pertaining to the interest of the TTHMUA, as necessary, from March 1, 2025 to February 28, 2026. Proposals are being solicited through a fair and open process in accordance with N.J.S.A. 19:44A-20.4 et seq. The required submittal forms to be submitted with the RPF’s can be found on our website at www.hillsboroughmua-nj.org. Proposals will be evaluated by TTHMUA based on the most advantageous, price and other factors considered. The evaluation will consider: a. Experience and reputation in the field and licensed to practice law in the State of New Jersey for a minimum of twenty (20) years. b. Experience in the field of Authority law representing Authorities in preparing bond ordinances, note issues and bond issues for a minimum of twenty (20) years. c. Knowledge of the TTHMUA and the subject matter to be addressed under the contract. d. Availability to accommodate any required meetings of the Authority. e. References in general; please note any experience in Authority law. f. Compensation proposal. g. Other factors if demonstrated to be in the best interest of the TTHMUA. Selection of Bond Counsel shall be based solely on the TTHMUA’s evaluation of the submitted material, and the criteria set forth in this document. The TTHMUA reserves the right to negotiate the terms and conditions of the contract with the successful firm or firms to obtain the most advantageous outcome for the TTHMUA. Proposals (two copies) must be submitted in writing in a sealed envelope bearing the name and address of the Proposer and the words “Bond Counsel.” Proposals shall be sent to the Qualified Purchasing Agent of the Township of Hillsborough Municipal Utilities Authority, located at 301 Towne Centre Drive, Hillsborough NJ 08844 no later than Wednesday, February 5, 2025, at 2:00 P.M., at which time all proposals shall be opened. 1x, HB, 12/27/24, Fee:$38.35 Affidavit Fee:$15.00

SHERIFF'S SALE By virtue of a Writ of execution, to me directed, issued out of the SUPERIOR COURT OF NEW JERSEY CHANCERY DIVISION, CAMDEN COUNTY, DOCKET NO. F00332424 at Public Venue on WEDNESDAY the 15TH Day of JANUARY, 2025 A.D. at 12 o'clock, LOCAL TIME, noon of said day, at 520 MARKET ST, CAMDEN, NJ 08102 CAMDEN CITY COUNCIL CHAMBERS ON 2ND FLOOR. The property to be sold is located within the TOWNSHIP OF WINSLOW, County of CAMDEN and State of New Jersey. Commonly known as: 6 HEMLOCK LN, SICKLERVILLE, NJ 08081; Tax Lot No. 3, Block No. 2901.04 on the official Tax Map of the TOWNSHIP OF WINSLOW Dimensions of Lot: .26AC Nearest Cross Street: CONIFER WAY *Subject to any unpaid taxes, municipal liens or other charges, and any such taxes, charges, liens, insurance premiums or other advances made by plaintiff prior to this sale. All interested parties are to conduct and rely upon their own independent investigation to ascertain whether or not any outstanding interest remain of record and/or have priority over the lien being foreclosed and, if so the current amount due thereon. If the sale is set aside for any reason, the Purchaser at the sale shall be entitled only to a return of the deposit paid. The Purchaser shall have no further recourse against the Mortgagor, the Mortgagee, or the Mortgagee's attorney. The occupancy status of the subject property is: Owner Occupied Plaintiff's good faith estimate of its upset price is $277,534.56 THE SHERIFF HEREBY RESERVES THE RIGHT TO ADJOURN THIS SALE WITHOUT FURTHER NOTICE THROUGH PUBLICATION. Surplus Money: If after the sale and satisfaction of the mortgage debt, including costs and expenses, there remains any surplus money, the money will be deposited into the Superior Court Trust Fund and any person claiming the surplus, or any part thereof, may file a motion pursuant to Court Rules 4:64-3 and 4:57-2 stating the nature and extent of that person's claim and asking for an order directing payment of the surplus money. The Sheriff or other person conducting the sale will have information regarding the surplus, if any. The judgment sought to be satisfied by the sale is: "APPROXIMATELY" $280,305.86 TWENTY PERCENT DEPOSIT REQUIRED Seized as the property of MARK E. VOSS, ET AL., defendant(s), and taken in execution of U.S. BANK TRUST COMPANY, NATIONAL ASSOCIATION, AS TRUSTEE AS SUCCESSOR-IN- 1 NTEREST TO U.S. BANK NATIONAL ASSOCIATION AS TRUSTEE TO J.P. MORGAN MORTGAGE ACQUISITION CORP. 2005-FREl ASSE BACKED PASS-THROUGH CERTIFICATES SERIES2005-FRE1, plaintiff. GILBERT L. "Whip" WILSON SHERIFF Sheriff's Number: 24002670 DATED: 12/18, 12/25/24, 1/1, 1/8/25 Attorney: BROCK & SCOTT, PLLC 302 FELLOWSHIP ROAD SUITE 130 MOUNT LAUREL, NJ 08054. Prt’s Fee:$141.12 Affidavit Fee:$5.00

TOWNSHIP OF HILLSBOROUGH MUNICIPAL UTILITIES AUTHORITY REQUEST FOR QUALIFICATIONS & PROPOSAL PROFESSIONAL CONSULTING ENGINEERING SERVICES The Township of Hillsborough Municipal Utilities Authority (TTHMUA) is issuing a Request for Qualifications & Proposal (RFQ/RFP) from Engineering firms and Engineers licensed to practice in the State of New Jersey to provide professional engineering services to the TTHMUA. In addition to general civil engineering, the firm or engineer must provide environmental engineering services with proven expertise and experience in all phases of wastewater treatment (collection facilities), operation, design, permitting, collection / conveyance, construction / inspection, planning, management, plan review and any other engineering need for the TTHMUA from March 1, 2025 to February 28, 2026. Proposals are being solicited through a fair and open process in accordance with N.J.S.A. 19:44A-20.4 et seq. The required submittal forms to be submitted with the RPF’s can be found on our website at www.hillsboroughmua-nj.org. Proposals will be evaluated by TTHMUA based on the most advantageous, price and other factors considered. The evaluation will consider: a.) A minimum of twenty (20) years of experience of the firm in the field of wastewater; including documentation and references of at least five (5) similar appointments demonstrating familiarity with the services requested. b.) Knowledge of the TTHMUA and the subject matter to be addressed under the contract. c.) Qualifications and experience of the designated professional(s) and support staff, and the location of firm’s offices. Submit resumes for all key professionals proposed for this project. Resumes should not exceed three (3) pages in length. d.) Availability to accommodate any required meetings of the Authority. e.) Compensation: Provide actual salary hourly rates of all individuals proposed along with the % overhead and % profit multipliers proposed for this contract. Experience and Qualifications should demonstrate the ability to at a minimum provide the following services: 1. Preliminary and feasibility investigations and reports. 2. Metering and inspections, overseeing operation of flow meters and analysis of data. 3. Ability to oversee on-going infiltration / inflow detection and remediation program. 4. Design of new and rehabilitated laterals, gravity mains, force mains, and all aspects and components of pump stations. 5. Preparation of Construction Contract Documents (plans and specifications). 6. Construction Observation Services. 7. Review Developer applications and support documents (plans, specifications, reports, and performance bonds). 8. Review / observe project status with respect to the reduction and / or release of performance bonds. 9. Assist the Executive Director and his assignees as needed. 10. Attendance at Authority meetings. 11. Assistance to Authority Attorney as needed. 12. Assistance to Authority in securing permits and grants from other governmental agencies. 13. Represent the TTHMUA before local, State and Federal agencies relative to environmental matters. 14. Perform, if requested, an annual inspection of the system and prepare an annual maintenance and operations report. 15. Perform other wastewater engineering related tasks as requested by TTHMUA and in the best interest of TTHMUA. Selection shall be based solely on the TTHMUA’s evaluation of the submitted materials, and the criteria set forth in this document. The TTHMUA reserves the right to negotiate the terms and conditions of the contract with the successful firm or firms to obtain the most advantageous outcome for the TTHMUA. The TTHMUA reserves the right to select multiple firms to fulfill its needs. Proposals (two copies) must be submitted in writing in a sealed envelope bearing the name and address of the Proposer and the words “Professional Consulting Engineering Services”. Proposals shall be sent to the Qualified Purchasing Agent of the Township of Hillsborough Municipal Utilities Authority, located at 301 Towne Centre Drive, Hillsborough NJ 08844 no later than Wednesday, February 5, 2025, at 2:00 P.M., at which time all proposals shall be opened. 1x, HB , 12/27/24, Fee:$65.85 Affidavit Fee:$15.00

PUBLIC NOTICE OF THE 2025 BUDGET HEARING FOR THE COMMISSIONERS OF FIRE DISTRICT NO. 1 IN THE TOWNSHIP OF SOUTH BRUNSWICK, COUNTY OF MIDDLESEX PLEASE TAKE NOTICE that The Commissioners of Fire District No. 1 in the Township of South Brunswick, County of Middlesex, pursuant to New Jersey statutory law, shall hold a public hearing relative to the proposed 2025 Annual Budget for the fire district on January 13, 2025 at 6:30 p.m. at the Kendall Park Firehouse, New Road, Kendall Park, New Jersey. The purpose of the budget hearing is to provide any and all taxpayers of the fire district and all persons having an interest herein, an opportunity to present objections to the said annual budget prior to its final adoption by the Commissioners. Final adoption of the budget by the Commissioners may occur at this meeting on January 13, 2025 after the closing of the hearing concerning said budget. Said budget may be adopted in that exact form as previously approved by the Commissioners or may be amended during or after the public hearing concerning the budget. A copy of said proposed annual budget, which was previously approved by the Commissioners at a regular meeting, said meeting having been duly advertised in accordance with the Open Public Meetings Act of the State of New Jersey, shall be available to each and every person requesting same during the week preceding said public hearing and may be obtained from the Commissioners’ attorney, Richard M. Braslow, 516 Fielders Lane, Toms River, New Jersey, 08755, (732) 341-7537, Monday through Friday, between the hours of 9 a.m. and 5 p.m. BY: Kris Olson, Secretary/Clerk The Commissioners of Fire District No. 1 Township of South Brunswick, County of Middlesex 1x, PP, 12/27/24, Fee:$23.89 Affidavit Fee:$15.00

PUBLIC NOTICE The Princeton Board of Education Reorganization meeting on January 7th, 2025; will start at 5:30 pm. It was originally scheduled for 6 pm. Matt Bouldin Business Administrator/Board Secretary 1x, PP, 12/27/24, Fee:$5.56

SHERIFF'S SALE BY virtue of o Writ of execution, to me directed, issued out of the SUPERIOR COURT OF NEW JERSEY CHANCERY DIVISION, CAMDEN COUNTY, DOCKET NO. F00397324 at Public Venue on WEDNESDAY the 15TH Day of JANUARY, 2025 AD. at 12 o'clock, LOCAL TIME, noon of said day, at 520 MARKET ST, CAMDEN, NJ 08102 CAMDEN CITY COUNCIL CHAMBERS ON 2ND FLOOR. The property to be sold is located within the BOROUGH OF PINE HILL, County of CAMDEN and State of New Jersey. Commonly known as: 10 HANCOCK LANE, BERLIN, NJ 08009; Tax Lot No. l, Block No. 116.02 Dimensions of Lot: (APPROX.) 75 FEET BY 102 FEET Nearest Cross Street: APPROXIMATELY 50 FEET TO THE NORTHEASTERLY SIDELINE OF HANCOCK LANE FROM THE NORTHWESTERLY SIDELINE OF WASHINGTON AVENUE Upset Bid Amount: $46,565.89 Occupancy Status: Unknown Amount Due for Taxes: Taxes due in the approximate amount of $7,064.77 as of 9fl!:124 Sale may be subject to subsequent taxes, liens, utilities and interest since 9fl!:124 Water/Sewer Due and owing in the approximate amount of $35.00 as of 9/25/24 Subject to: All unpaid municipal taxes, assessments, liens and other charges; any set of facts which an accurate survey would disclose; Any restrictions or covenants on record which run with the land; Rights of the United States of America, if any; Any condominium lien Priority pursuant to NJSA 46:88-21,if any; Any outstanding PUD or Homeowner's Association dues or fees, if any; Any occupants or persons in possession of the property, if any; Additional municipal charges, liens, taxes or tax sale certificates and insurance, if any; and any such taxes, municipal liens or other charges liens, insurance premiums or other advances made by plaintiff prior to this sale. The amount of unpaid taxes municipal liens and other charges can be obtained from the local taxing authority. All interested parties are to conduct and rely upon their own independent investigation to ascertain whether or not any outstanding interest remain of record and/or have priority over the lien being foreclosed and, if so the current amount due thereon. **If the sale is set aside for any reason, the Purchaser at the sale shall be entitled only to a return of the deposit paid. The Purchaser shall have no further recourse against the Mortgagor, the Mortgagee, or the Mortgagee's attorney. As the above description does not constitute a full legal description, said full legal description is annexed to that certain mortgage recorded in the Camden County Clerk's Office in Book 7007 at Page 993, et seq., New Jersey, and the Writ of Execution on file with the Sheriff of Camden County. For interested parties regarding Sheriff's Sale, please contact Auction.com at (800) 793-6107 or at www.Auction.com THE SHERIFF HEREBY RESERVES THE RIGHT TO ADJOURN THIS SALE WITHOUT FURTHER NOTICE THROUGH PUBLICATION. Surplus Money: If after the sale and satisfaction of the mortgage debt, including costs and expenses, there remains any surplus money, the money will be deposited into the Superior Court Trust Fund and any person claiming the surplus, or any part thereof, may file a motion pursuant to Court Rules 4:64-3 and 4:57-2 stating the nature and extent of that person's claim and asking for an order directing payment of the surplus money. The Sheriff or other person conducting the sale will have information regarding the surplus, if any. The judgment sought to be satisfied by the sale is: "APPROXIMATELY" $49,966.27 TWENTY PERCENT DEPOSIT REQUIRED Seized as the property of DAVID DOUGHERTY, defendant(s), and taken in execution of FAY SERVICING, LLC, plaintiff. GILBERT L. "Whip" WILSON SHERIFF Sheriff's Number: 24002735 DATED: 12/18, 12/25/24, 1/1, 1/8/25, Attorney: GROSS POLOWY, LLC 1775 WEHRLE DRIVE SUITE 100 WILLIAMSVILLE NY 14221 Prt’s Fee:$184.80 Affidavit Fee:$5.00

LEGAL NOTICE NOTICE IS HEREBY GIVEN that the Princeton Zoning Board of Adjustment at its meeting on December 11, 2024, adopted the Findings of Fact, Conclusions and Resolution for the following application: Name: Leverly Properties LLC-Owner/Applicant File: Z24-539 Address: 7 Park Place; Block 28.01, Lot 3.01 Nature of Application: D (4) variance to allow a floor area ratio of 63.36% and bulk variances to permit alterations and additions to an existing non-compliant single-family dwelling Determination: Approved Copies of the documents are posted in the municipal website https://princetonnj.gov/DocumentCenter/Index/448 and on file in the Princeton Zoning Department, 400 Witherspoon St.; Princeton, NJ and may be viewed during normal business hours. 1x, PP, 12/27/24, Fee:$21.11 Affidavit Fee:$15.00

PUBLIC NOTICE Notice is hereby given that bid proposals will be received from Bidders classified under N.J.S.A. 27:7-35.2 via the Internet until 10:00:59 A.M. on 1/7/25 downloaded, and publicly opened and read, in the CONFERENCE ROOM-A, 1st Floor F & A Building, New Jersey Department of Transportation, 1035 Parkway Avenue, Trenton, NJ 08625; for: Maintenance Job Order Contracting (JOC) Bridge Repair, Statewide - 2024, Various Locations, Burlington, Essex, Mercer & Union Counties Federal Project No: D00S(932) DP No: 24472 Bidders are required to comply with the requirements of Title VI of the Civil Rights Act of 1964. Specifically, the contractor, sub recipient or subcontractor shall not discriminate on the basis of race, color, national origin, or sex in the performance of this contract. The contractor shall carry out applicable requirements of 49 C.F.R. Part 26 in the award and administration of DOT-assisted contracts. Failure by the contractor to carry out these requirements is a material breach of this contract, which may result in the termination of this contract or such other remedy as the recipient deems appropriate. Pursuant to N.J.S.A. 52:32-44, contractor must submit the Department of Treasury, Division of Revenue Business Registration of the contractor and any named subcontractors prior to contract award or authorization. Pursuant to N.J.S.A. 34:11-56.51, contractors must be registered with the New Jersey Department of Labor, Division of Wage and hour Compliance at the time of bid. The Department, in accordance with Title VI Civil Rights Act of 1964, 78 Stat. 252 U.S.C., 49 C.F.R., Parts 21 and 23 issued pursuant to such Act, and Section 504 of the Rehabilitation Act of 1973 will afford minority business enterprises full opportunity to submit bids in response to this invitation and will not discriminate against any bidder on the grounds of race, color, sex, national origin, or handicap in the project award. Plans, specifications, any addenda to the specifications, and bidding information for the proposed work are available at Bid Express website www.bidx.com. You must subscribe to use this service. To subscribe, follow the instructions on the web site. Fees apply to downloading documents and plans and bidding access. The fee schedule is available on the web site. All fees are directly payable to Bid Express. Plans, specifications, any addenda to the specifications, and bidding information may be inspected (BUT NOT OBTAINED) by contracting organizations at our various Design Field Offices at the following locations: 200 Stierli Court One Executive Campus Rt. 70 West Mt. Arlington, NJ 07856 Cherry Hill, NJ 08002 Phone: 973-601-6690 Phone: 856-486-6623 New Jersey Department of Transportation Division of Procurement Bureau of Construction Services 1035 Parkway Avenue PO Box 600 Trenton, NJ 08625 3x, CP, 12/13, 12/20, 12/27/24, Fee:$133.41

CALENDAR YEAR 2025 ANNUAL NOTICE OF REGULARLY SCHEDULED MEETINGS OF THE PUBLIC BODIES OF MONROE TOWNSHIP In accordance with the requirements of the Open Public Meetings Act, the schedule of Regular Meetings of the Public Bodies of Monroe Township for the Calendar Year 2025 are as follows and will be held in the Monroe Township Municipal Complex, 1 Municipal Plaza unless otherwise stated. If the need arises, all meetings may be held via zoom. If so, the zoom link will be provided on the Monroe Township website www.monroetwp.com on the Calendar under each specific meeting date. A.D.A. COMMITTEE: Three times per year; First Thursday in March, June & September at 10:00 am in the Court Room. AFFORDABLE HOUSING BOARD: Four times per year; Second Wednesday in January, April, July and October at 6:30 pm in the Court Room. COMMISSION ON AGING: Bi-monthly (every 2 months), starting in January, the second Tuesday of each month, at 9:00 a.m in the Conference Room at the Senior Center, 12 Halsey Reed Road. There are no meetings in July and August. CULTURAL ARTS COMMISSION: Third Monday of each month, except January and February, which will be held January 14th and February 11th at 7:00 p.m., on the lower level. ECONOMIC DEVELOPMENT ADVISORY BOARD January 15, March 19, May 21, August 20, October 15, and November 19 at 6:30 p.m. in the Court Room. ENVIRONMENTAL COMMISSION: First Wednesday of each month at 7:00 p.m. on the lower level. There will be no July Meeting. HEALTH ADVISORY BOARD Last Wednesday of January, March, May, July, September and November at 6:30 p.m. in the Court Room. HISTORIC PRESERVATION Second Monday of each month at 7:00pm in the Lower Level Conference Room with the exception of the June meeting taking place at the Dey Farm Historic Site located at 401 Federal Road, Monroe Township. There will be no meetings in February, October or December. HUMAN RELATIONS COMMISSION: Second Tuesday of each month at 4:30 p.m. in the Court Room. There will be no meetings in May, July, August and December. INSURANCE FUND COMMISSION: April 2, August 6, and December 3 at 10:00 a.m. via zoom. LIBRARY BOARD OF TRUSTEES: January 21, February 18, March 18, April 15, May 20, June 17, July 15, September 16, October 21, November 18 and December 16 at 6:30 pm in the Program Room at the Library. There will be no meetings in August. MUNICIPAL COURT: Every Tuesday of the month at 9:30 a.m. via zoom and in person; 4th Tuesday of every month – all day session via zoom and in person. Court will not be held on Legal Holidays. N.J. TRAINING SCHOOL FOR BOYS CITIZENS REVIEW BOARD Two times per year; Wednesday March 12th and September 10th at 6:30 pm in the Court Room. OPEN SPACE AND FARMLAND PRESERVATION COMMISSION Second Wednesday in February and May and Third Wednesday in October at 6:30 p.m. in the lower-level conference room. PLANNING BOARD: Fourth Thursday of each month at 6:30 p.m. in the Court Room, except there is no November meeting and December meeting to be held the first Thursday of the month on December 4th. SHADE TREE COMMISSION: February 4, April 1, August 5, October 7 and December 2 at 7:00 p.m. in the Planning Conference Room. TOWNSHIP COUNCIL All meetings will be a combined agenda/regular meeting. The agenda meeting will begin at 6:30 p.m. with the regular meeting to immediately follow in the Council Chambers. The dates are as follows: January 6, January 29, March 3, April 7, May 5, June 4, June 30, August 4, September 3, October 6, November 5, December 1, and December 22. RECREATION ADVISORY BOARD: Second Monday of each month, except for October, November and December which will be held on the Third Monday, at 7:00 p.m. in the Community Center, 120 Monmouth Road. There will be no meetings in July & August. ZONING BOARD OF ADJUSTMENT: Last Tuesday of each month at 6:30 p.m. in the Court Room. except there is no November meeting and December meeting to be held the first Tuesday of the month on December 2nd. CHRISTINE ROBBINS, RMC/CMR Monroe Township Clerk 1x, CP, 12/27/24, Fee:$101.59